Court of Appeals for the Federal Circuit December 6, 1993, 92-1430 (Interstate General Government Contractors, Inc. v. Togo West, Secretary of the Army)

MICHEL, Circuit Judge.

Interstate General Government Contractors, Inc. (IGGC) appeals from a decision of the Armed Services Board of Contract Appeals (Board) denying IGGC’s claim for an equitable adjustment for alleged unabsorbed home office overhead caused by the government’s delay in issuing a notice to proceed (NTP) on a contract to renovate army barracks.

Interstate Gen.